|• 10-Q • SECTION 302 CEO CERTIFICATION • SECTION 302 CFO CERTIFICATION • SECTION 906 CEO CERTIFICATION • SECTION 906 CFO CERTIFICATION • XBRL INSTANCE DOCUMENT • XBRL TAXONOMY EXTENSION SCHEMA DOCUMENT • XBRL TAXONOMY EXTENSION CALCULATION LINKBASE DOCUMENT • XBRL TAXONOMY EXTENSION DEFINITION LINKBASE DOCUMENT • XBRL TAXONOMY EXTENSION LABEL LINKBASE DOCUMENT • XBRL TAXONOMY EXTENSION PRESENTATION LINKBASE DOCUMENT|
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
For the quarterly period ended September 30, 2012
For the transition period from _____ to _____
Commission File Number 1-33146
(a Delaware Corporation)
601 Jefferson Street
Houston, Texas 77002
(Address of Principal Executive Offices)
Telephone Number – Area Code (713) 753-3011
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes x No ¨
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes x No ¨
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ¨ No x
As of October 11, 2012, there were 147,553,868 shares of KBR, Inc. common stock, $0.001 par value per share, outstanding.
Forward-Looking and Cautionary Statements
This report contains certain statements that are, or may be deemed to be, “forward-looking statements” within the meaning of Section 27A of the Securities Act of 1933, as amended, and Section 21E of the Securities Exchange Act of 1934, as amended. The Private Securities Litigation Reform Act of 1995 provides safe harbor provisions for forward looking information. Some of the statements contained in this quarterly report are forward-looking statements. All statements other than statements of historical fact are, or may be deemed to be, forward-looking statements. The words “believe,” “may,” “estimate,” “continue,” “anticipate,” “intend,” “plan,” “expect” and similar expressions are intended to identify forward-looking statements. Forward-looking statements include information concerning our possible or assumed future financial performance and results of operations.
We have based these statements on our assumptions and analyses in light of our experience and perception of historical trends, current conditions, expected future developments and other factors we believe are appropriate in the circumstances. Forward-looking statements by their nature involve substantial risks and uncertainties that could significantly affect expected results, and actual future results could differ materially from those described in such statements. While it is not possible to identify all factors, factors that could cause actual future results to differ materially include the risks and uncertainties disclosed in our 2011 Annual Report on Form 10-K contained in Part I under “Risk Factors”.
Many of these factors are beyond our ability to control or predict. Any of these factors, or a combination of these factors, could materially and adversely affect our future financial condition or results of operations and the ultimate accuracy of the forward-looking statements. These forward-looking statements are not guarantees of our future performance, and our actual results and future developments may differ materially and adversely from those projected in the forward-looking statements. We caution against putting undue reliance on forward-looking statements or projecting any future results based on such statements or on present or prior earnings levels. In addition, each forward-looking statement speaks only as of the date of the particular statement, and we undertake no obligation to publicly update or revise any forward-looking statement.
PART I. FINANCIAL INFORMATION
Item 1. Financial Statements
Condensed Consolidated Statements of Income
(In millions, except for per share data)
See accompanying notes to condensed consolidated financial statements.
Condensed Consolidated Statements of Comprehensive Income
See accompanying notes to condensed consolidated financial statements.
See accompanying notes to condensed consolidated financial statements.
Condensed Consolidated Statements of Cash Flows (In millions, Unaudited)
See accompanying notes to condensed consolidated financial statements.
Note 1. Description of Business and Basis of Presentation
KBR, Inc., a Delaware corporation, was formed on March 21, 2006. KBR, Inc. and its subsidiaries (collectively, “KBR”) is a global engineering, construction and services company supporting the energy, hydrocarbons, government services, minerals, civil infrastructure, power, industrial and commercial markets. Headquartered in Houston, Texas, we offer a wide range of services through our Hydrocarbons, Infrastructure, Government and Power (“IGP”), Services and Other business segments. See Note 5 for additional financial information about our business segments.
The accompanying unaudited condensed consolidated financial statements have been prepared in accordance with the rules of the United States Securities and Exchange Commission (“SEC”) for interim financial statements and do not include all annual disclosures required by accounting principles generally accepted in the United States (“U.S. GAAP”). These condensed consolidated financial statements should be read in conjunction with the audited consolidated financial statements and notes thereto included in our Annual Report on Form 10-K for the fiscal year ended December 31, 2011 filed with the SEC. We believe that the presentation and disclosures herein are adequate to make the information not misleading, and the condensed consolidated financial statements reflect all normal adjustments that management considers necessary for a fair presentation of our condensed consolidated results of operations, financial position and cash flows. Operating results for interim periods are not necessarily indicative of results to be expected for the full fiscal year 2012 or any other future periods.
The preparation of our condensed consolidated financial statements in conformity with GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities at the balance sheet dates and the reported amounts of revenue and costs during the reporting periods. Actual results could differ materially from those estimates. On an ongoing basis, we review our estimates based on information currently available, and changes in facts and circumstances may cause us to revise these estimates.
Our condensed consolidated financial statements include the accounts of majority-owned, controlled subsidiaries and variable interest entities where we are the primary beneficiary. The equity method is used to account for investments in affiliates in which we have the ability to exert significant influence over the operating and financial policies of the entity. The cost method is used when we do not have the ability to exert significant influence. Intercompany accounts and transactions are eliminated.
Note 2. Income per Share
Basic income per share is based upon the weighted average number of common shares outstanding during the period. Dilutive income per share includes additional common shares that would have been outstanding if potential common shares with a dilutive effect had been issued, using the treasury stock method. A reconciliation of the number of shares used for the basic and diluted income per share calculations is as follows:
For purposes of applying the two-class method in computing earnings per share, there were no earnings allocated to participating securities for the three months ended September 30, 2012 and $0.8 million for the three months ended September 30, 2011. Net earnings allocable to participating securities was $0.4 million and $1.8 million for the nine months ended September 30, 2012 and 2011, respectively. The diluted earnings per share calculation did not include 2.4 million and 1.3 million anti-dilutive weighted average shares for the three and nine months ended September 30, 2012, respectively. The diluted earnings per share calculation did not include 0.7 million and 0.5 million anti-dilutive weighted average shares for the three and nine months ended September 30, 2011, respectively.
Note 3. Business Combinations and Other Transactions
M.W. Kellogg Limited (“MWKL”). On December 31, 2010, we obtained control of the remaining 44.94% interest in our MWKL subsidiary located in the U.K. for £107 million subject to certain post-closing adjustments. The acquisition was recorded as an equity transaction that reduced noncontrolling interests, accumulated other comprehensive income (“AOCI”) and additional paid-in capital by $180 million. We recognized direct transaction costs associated with the acquisition of $1 million as a charge to additional paid in capital. The initial purchase price of $164 million was paid on January 5, 2011. During the third quarter of 2011, we settled various post-closing adjustments that resulted in a decrease to “Paid-in capital in excess of par” of $5 million. We also agreed to pay the former noncontrolling interest 44.94% of future proceeds collected on certain receivables owed to MWKL. Additionally, the former noncontrolling interest agreed to indemnify us for 44.94% of certain MWKL liabilities to be settled and paid in the future. As of September 30, 2012, we have liabilities of $8 million classified on our condensed consolidated balance sheet as “Other noncurrent liabilities” and $1 million classified on our balance sheet as “Other current liabilities” reflecting our estimate of 44.94% of future proceeds from certain receivables owed to MWKL.
LNG Joint Venture. On January 5, 2011, we sold our 50% interest in a joint venture to our joint venture partner for $22 million. The joint venture was formed to execute an EPC contract for construction of an LNG plant in Indonesia. We recognized a gain on the sale of our interest of $8 million which is included in “Equity in earnings of unconsolidated affiliates, net” in our condensed consolidated income statement for the nine months ended September 30, 2011.
Note 4. Percentage-of-Completion Contracts
Claims and unapproved change orders
The amounts of claims and unapproved change orders included in determining the profit or loss on contracts and recorded in current and noncurrent unbilled receivables on uncompleted contracts are as follows:
As of September 30, 2012, the probable claims and unapproved change orders related to several projects. Included in the table above are probable claims associated with the reimbursable portion of an EPC contract to construct an LNG facility for which we have recognized additional contract revenue totaling $106 million. The contract claims on this project represent incremental subcontractor costs incurred and we believe we have legal entitlement to recover these costs from the customer under the terms of the EPC contract. Contracts with probable claims that will likely not be settled within one year totaled $18 million at September 30, 2012 and $19 million at December 31, 2011, and are reflected as a noncurrent asset in “Noncurrent unbilled receivables on uncompleted contracts” in our condensed consolidated balance sheets. Other probable claims and unapproved change orders that we believe will be settled within one year, have been recorded as a current asset in “Unbilled receivables on uncompleted contracts” in our condensed consolidated balance sheets. See Note 8 for a discussion of U.S. government contract claims, which are not included in the table above.
For our unconsolidated subsidiaries, our share of claims and unapproved change orders was $4 million and $41 million, respectively, for the nine months ended September 30, 2012.
Many of our engineering and construction contracts have milestone due dates that must be met or we may be subject to penalties for liquidated damages if claims are asserted and we were responsible for the delays. These generally relate to specified activities that must be met within a project by a set contractual date or achievement of a specified level of output or throughput of a plant we construct. Each contract defines the conditions under which a customer may make a claim for liquidated damages. However, in some instances, liquidated damages are not asserted by the customer, but the potential to do so is used in negotiating claims and closing out the contract. Based upon our evaluation of our performance and other legal analysis, we have not accrued for possible liquidated damages related to several projects totaling $3 million at September 30, 2012 and $11 million at
December 31, 2011, that we could incur based upon completing the projects as currently forecasted.
Note 5. Business Segment Information
We provide a wide range of services, but the management of our business is heavily focused on major projects within each of our reportable segments. At any given time, a relatively few number of projects and joint ventures represent a substantial part of our operations. Our equity in earnings and losses of unconsolidated affiliates that are accounted for using the equity method of accounting is included in revenue of the applicable segment.
Reportable segment performance is evaluated by our chief operating decision maker using operating segment income which is defined as operating segment revenue less the cost of services and segment overhead directly attributable to the operating segment. Intersegment revenues are eliminated from operating segment revenues. Reportable segment income excludes certain cost of services and general and administrative expenses directly attributable to the operating segment that is managed and reported at the corporate level, and corporate general and administrative expenses. Labor cost absorption in the following table represents income or expense generated by our central service labor and resource groups for amounts charged to the operating segments.
The table below presents information on our reportable business segments.
(a) - As a result of our interim goodwill impairment test, we recorded a noncash goodwill impairment charge in our Minerals reporting unit, which is part of our IGP segment, of 178 million in the three and nine months ended September 30, 2012. The impact of this goodwill impairment resulted in a reduction of our IGP segment's goodwill by the amount of the impairment charge from the carrying value of $403 million at December 31, 2011.
Note 6. Goodwill
Interim Goodwill Impairment Review
We perform our annual goodwill impairment review as of October 1 of each year and also perform interim impairment reviews if events occur or circumstances change that indicate it is likely that the fair value of a reporting unit is below its carrying amount. Our 2011 annual goodwill impairment review, performed as of October 1, 2011, did not indicate an impairment of goodwill for any of our reporting units. In the third quarter of 2012, during the course of our annual strategic planning process, we identified deterioration in economic conditions in the minerals markets and less than expected actual and projected income and cash flows for the Minerals reporting unit. This resulted in a reduction of our forecasts of the sales, operating income and cash flows expected in 2013 and beyond. Therefore, we performed an interim goodwill impairment test during the third quarter of 2012.
The first step in performing a goodwill impairment test is to identify potential impairment by comparing the estimated fair value of the reporting unit to its carrying value. The result of the first step of our goodwill impairment test indicated the carrying value of our Minerals reporting unit exceeded its fair value. Therefore, we performed the second step of the goodwill impairment test in order to measure the amount of the potential impairment loss. The second step of the goodwill impairment test compares the implied fair value of the reporting unit's goodwill to the carrying value of that goodwill. We determined the implied fair value of the goodwill in the same manner as we use in determining the amount of goodwill to be recognized in a business combination. Applying this methodology, we assigned the fair value of the Minerals reporting unit estimated in step one to all the assets and liabilities of the reporting unit. The implied fair value of the Minerals reporting unit's goodwill is the excess of the fair value of the reporting unit over the amounts assigned to its assets and liabilities. As a result of our interim goodwill impairment test, we recorded a noncash goodwill impairment charge in our Minerals reporting unit, which is part of our IGP segment, of $178 million in this quarter. Due to this impairment goodwill for the reporting unit decreased from its December 31, 2011 balance of $263 million to $85 million at September 30, 2012. We will continue to monitor the recoverability of our goodwill. See Note 13 for additional information on our fair value measurements related to our interim goodwill impairment test.
To arrive at the Minerals reporting unit's future cash flows, we use estimates of economic and market information, including growth rates in revenues, costs, and estimates of future expected changes in operating margins, tax rates, and cash expenditures. Other significant estimates and assumptions include terminal value growth rates, future estimates of capital expenditures and changes in future working capital requirements. Under the income approach, we applied a risk-adjusted discount rate of 16% to the future cash flows from the Minerals reporting unit. The market approach estimates fair value by applying earnings and revenue market multiples to the reporting unit's operating performance for the trailing twelve-month period. The market multiples are derived from comparable publicly traded companies with operating and investment characteristics similar to those of our Minerals reporting units. The income approach estimates fair value by discounting the reporting unit's estimated future cash flows using a weighted-average cost of capital that reflects current market conditions and the risk profile of each business unit. In addition to the earnings multiples and the discount rates disclosed above, certain other judgments and estimates are used to prepare the goodwill impairment test. If market conditions change compared to those used in our market approach, or if actual future results of operations fall below the projections used in the income approach, our goodwill could become further impaired in the future.
Note 7. Committed Cash
Cash and equivalents include cash related to contracts in progress as well as cash held by our joint ventures that we consolidate for accounting purposes. Joint venture cash balances are limited to joint venture activities and are not available for general cash needs, use on other projects or distributions to us without proper approval by the respective joint venture. Cash held by our joint ventures that we consolidate for accounting purposes totaled $201 million at September 30, 2012 and $244 million at December 31, 2011. We expect to use the cash on these projects to pay project costs.
Note 8. United States Government Contract Work
We provide substantial work under our government contracts to the United States Department of Defense (“DoD”) and other governmental agencies. These contracts include our worldwide United States Army logistics contracts, known as LogCAP III and IV.
Given the demands of working in Iraq and elsewhere for the U.S. government, as discussed further below, we have disagreements and have experienced performance issues with the various government customers for which we work. When performance issues arise under any of our government contracts, the government retains the right to pursue remedies, which could include termination, under any affected contract. If any contract were so terminated, our ability to secure future contracts could be adversely affected, although we would receive payment for amounts owed for our allowable costs under cost-reimbursable contracts. Other remedies that could be sought by our government customers for any improper activities or performance issues include sanctions such as forfeiture of profits, suspension of payments, fines, and suspensions or debarment from doing business with the government. Further, the negative publicity that could arise from disagreements with our customers or sanctions as a result thereof could have an adverse effect on our reputation in the industry, reduce our ability to compete for new contracts, and may also have a material adverse effect on our business, financial condition, results of operations, and cash flow.
We have experienced and expect to be a party to various claims against us by employees, third parties, soldiers, subcontractors and others that have arisen out of our work in Iraq such as claims for wrongful termination, assaults against employees, personal injury claims by third parties and army personnel, and subcontractor claims. While we believe we conduct our operations safely, the environments in which we operate often lead to these types of claims. We believe the vast majority of these types of claims are governed by the Defense Base Act or precluded by other defenses. We have a dispute resolution program under which most employment claims are subject to binding arbitration. However, as a result of amendments to the Department of Defense
Appropriations Act of 2010, certain types of employee claims cannot be compelled to binding arbitration. An unfavorable resolution or disposition of these matters could have a material adverse effect on our business, results of operations, financial condition and cash flow.
In accordance with the provisions of the LogCAP III contract, we recognize revenue on our services rendered on a task order basis based on either a cost-plus-fixed-fee or cost-plus-base-fee and award fee arrangement. The fees are determined as a percentage rate applied to a negotiated estimate of the total costs for each task order. Commencing in the fourth quarter of 2009, we stopped accruing award fees and began recognizing them only upon receipt of the award fee letter due to the inability to reliably estimate the amount of fees to be awarded. During the first quarter of 2011, we were awarded and recognized revenue of $16 million for award fees for the periods of performance from March 2010 through August 2010 on task orders in Iraq. In September 2011, we received an award fee of $22 million representing approximately 80% of the available award fee pool for the period of performance from September 2010 through February 2011 on task orders in Iraq, which was recorded as an increase to revenue in the third quarter of 2011. No award fee pools are available for the periods of performance subsequent to February 2011.
In August of 2010, we executed a contract modification to the LogCAP III contract on the base life support task order in Iraq that resulted in an increase to our base fee on costs incurred and an increase in the maximum award fee on negotiated costs for the period of performance from September 2010 through February 2011. During the first quarter of 2011, we finalized negotiations with our customer and converted the task order from cost-plus-base-fee and award fee to cost-plus-fixed-fee for the period of performance beginning in March 2011. We recognize revenues for the fixed-fee component on the basis of proportionate performance as services are performed.
Government Compliance Matters
The negotiation, administration, and settlement of our contracts with the U.S. Government, consisting primarily of DoD contracts, are subject to audit by the Defense Contract Audit Agency (“DCAA”), which serves in an advisory role to the Defense Contract Management Agency (“DCMA”), which is responsible for the administration of our contracts. The scope of these audits include, among other things, the allowability, allocability, and reasonableness of incurred costs, approval of annual overhead rates, compliance with the Federal Acquisition Regulation (“FAR”) and Cost Accounting Standards (“CAS”), compliance with certain unique contract clauses, and audits of certain aspects of our internal control systems. Issues identified during these audits are typically discussed and reviewed with us, and certain matters are included in audit reports issued by the DCAA, with its recommendations to our customer’s administrative contracting officer (“ACO”). We attempt to resolve all issues identified in audit reports by working directly with the DCAA and the ACO. When agreement cannot be reached, the DCAA may issue a Form 1, “Notice of Contract Costs Suspended and/or Disapproved,” which recommends withholding the previously paid amounts or it may issue an advisory report to the ACO. KBR is permitted to respond to these documents and provide additional support. At September 30, 2012, we have open Form 1’s from the DCAA recommending suspension of payments totaling approximately $335 million associated with our contract costs incurred in prior years, of which $141 million has been withheld from our current billings. As a consequence, for certain of these matters, we have withheld $58 million from our subcontractors under the payment terms of those contracts. In addition, we have outstanding demand letters received from our customer requesting that we remit a total of $96 million of disapproved costs for which we do not believe we have a legal obligation to pay. We continue to work with our ACO’s, the DCAA and our subcontractors to resolve these issues. However, for certain of these matters, we have filed claims with the Armed Services Board of Contract Appeals (“ASBCA”) or the United States Court of Federal Claims (“U.S. COFC”).
KBR excludes from billings to the U.S. Government costs that are potentially unallowable, expressly unallowable, or mutually agreed to be unallowable, or not allocable to government contracts per applicable regulations. Revenue recorded for government contract work is reduced at the time we identify and estimate potentially refundable costs related to issues that may be categorized as disputed or unallowable as a result of cost overruns or the audit process. Our estimates of potentially unallowable costs are based upon, among other things, our internal analysis of the facts and circumstances, terms of the contracts and the applicable provisions of the FAR and CAS, quality of supporting documentation for costs incurred, and subcontract terms as applicable. From time to time, we engage outside counsel to advise us on certain matters in determining whether certain costs are allowable. We also review our analysis and findings with the ACO as appropriate. In some cases, we may not reach agreement with the DCAA or the ACO regarding potentially unallowable costs which may result in our filing of claims in various courts such as the ASBCA or the U.S. COFC. We only include amounts in revenue related to disputed and potentially unallowable costs when we determine it is probable that such costs will result in the collection of revenue. We generally do not recognize additional revenue for disputed or potentially unallowable costs for which revenue has been previously reduced until we reach agreement with the DCAA and/or the ACO that such costs are allowable.
Certain issues raised as a result of contract audits and other investigations are discussed below.
Private Security. In 2007, we received a Form 1 from the Department of the Army informing us of their intent to adjust payments under the LogCAP III contract associated with the cost incurred for the years 2003 through 2006 by certain of our subcontractors to provide security to their employees. Based on that notice, the Army withheld its initial assessment of $20 million. The Army based its initial assessment on one subcontract wherein, based on communications with the subcontractor, the Army estimated 6% of the total subcontract costs related to the private security. We subsequently received Form 1’s from the DCAA disapproving an additional $83 million of costs incurred by us and our subcontractors to provide security during the same periods. Since that time, the Army withheld an additional $25 million in payments from us bringing the total payments withheld to $45 million as of September 30, 2012, out of the Form 1’s issued to date of $103 million.
The Army indicated that they believe our LogCAP III contract prohibits us and our subcontractors from billing costs of privately armed security. We believe that, while the LogCAP III contract anticipates that the Army will provide force protection to KBR employees, it does not prohibit us or any of our subcontractors from using private security services to provide force protection to KBR or subcontractor personnel. In addition, a significant portion of our subcontracts are competitively bid fixed price subcontracts. As a result, we do not receive details of the subcontractors’ cost estimate nor are we legally entitled to it. Further, we have not paid our subcontractors any additional compensation for security services. Accordingly, we believe that we are entitled to reimbursement by the Army for the cost of services provided by us or our subcontractors, even if they incurred costs for private force protection services. Therefore, we do not agree with the Army’s position that such costs are unallowable and that they are entitled to withhold amounts incurred for such costs.
We have provided at the Army’s request information that addresses the use of armed security either directly or indirectly charged to LogCAP III. In 2007, we filed a complaint in the ASBCA to recover $44 million of the amounts withheld from us. In 2009, KBR and the Army agreed to stay the case pending further discussions with the DOJ as discussed further below. The ASBCA denied the Army’s latest request to stay the proceedings. In April 2012, the ASBCA ruled, as requested by KBR, that our contract with the Army does not prohibit the use of private security contractors by either KBR or its subcontractors. However, our motion to dismiss was denied on grounds that potential fact issues remain related to the reasonableness of the private security costs charged to the contract. Discovery on the remaining issues is in process and the next hearing is scheduled to occur in December 2012. We believe these sums were properly billed under our contract with the Army. At this time, we believe the likelihood that a loss related to this matter has been incurred is remote. We have not adjusted our revenues or accrued any amounts related to this matter. This matter is also the subject of a separate claim filed by the DOJ for alleged violation of the False Claims Act as discussed further below under the heading “Investigations, Qui Tams and Litigation.”
Containers. In June 2005, the DCAA recommended withholding certain costs associated with providing containerized housing for soldiers and supporting civilian personnel in Iraq. The DCMA agreed that the costs be withheld pending receipt of additional explanation or documentation to support the subcontract costs. During the first quarter of 2011, we received a Form 1 from the DCAA disapproving $25 million in costs related to containerized housing that had previously been deemed allowable. As of September 30, 2012, $51 million of costs have been suspended under Form 1’s of which $26 million have been withheld from us by our customer. We have withheld $30 million from our subcontractor related to this matter. In April 2008, we filed a counterclaim in arbitration against our LogCAP III subcontractor, First Kuwaiti Trading Company, to recover the $51 million we paid to the subcontractor for containerized housing as further described under the caption First Kuwaiti Trading Company arbitration below. During the first quarter of 2011, we filed a complaint before the ASBCA to contest the Form 1’s and recover the amounts withheld from us by our customer. We believe that the costs incurred associated with providing containerized housing are reasonable, and we intend to vigorously defend ourselves in this matter. We do not believe that we face a risk of significant loss from any disallowance of these costs in excess of the amounts we have withheld from subcontractors and the loss accruals we have recorded. At this time, we believe the likelihood that a loss in excess of the amount accrued for this matter is remote.
Dining facilities. In 2006, the DCAA raised questions regarding our billings and price reasonableness of costs related to dining facilities in Iraq. We responded to the DCMA that our costs are reasonable. As of September 30, 2012, we have outstanding Form 1’s from the DCAA disapproving $107 million in costs related to these dining facilities until such time we provide documentation to support the price reasonableness of the rates negotiated with our subcontractor and demonstrate that the amounts billed were in accordance with the contract terms. We believe the prices obtained for these services were reasonable and intend to vigorously defend ourselves on this matter. We filed claims in the U.S. COFC or ASBCA to recover $55 million of the $60 million withheld from us by the customer. In April 2012, the U.S. COFC ruled that KBR's negotiated price for certain DFAC services were not reasonable and that we are entitled to $12 million of the total $41 million withheld from us by our customer related to one of our subcontractors, Tamimi. As a result of this ruling, we recognized a noncash, pre-tax charge of $28 million as a reduction to revenue related to the disallowed portion of the questioned costs in the second quarter of 2012. We appealed the
U.S. COFC ruling. Prior to the U.S. COFC ruling, Tamimi filed for arbitration against us in 2009 to recover the payments we withheld from Tamimi pending the resolution of Form 1's with our customer. In December 2010, the arbitration panel ruled that our subcontract terms were not sufficient to hold retention from Tamimi for price reasonableness matters and awarded the subcontractor $38 million including interest and certain legal costs. We paid the award to Tamimi during the third quarter of 2011. We do not believe we have the ability to recover the disallowed portion of the questioned costs previously paid to Tamimi. With respect to the remaining questions raised regarding billing in accordance with contract terms, as of September 30, 2012, we believe it is reasonably possible that we could incur losses in excess of the amount accrued for possible subcontractor costs billed to the customer that were possibly not in accordance with contract terms. However, we do not believe we face a risk of significant loss from any disallowance of these costs in excess of amounts withheld from subcontractors. As of September 30, 2012, we had withheld $18 million in payments from several of our subcontractors pending the resolution of these remaining matters with our customer.
In March 2011, the DOJ filed a counterclaim in the U.S. COFC alleging KBR employees accepted bribes from Tamimi, in exchange for awarding a master agreement for DFAC services to Tamimi. The DOJ seeks disgorgement of all funds paid to KBR under the master agreement as well as all award fees paid to KBR under the related task orders. Trial in the U.S. COFC took place during the fourth quarter of 2011. In conjunction with the April 2012 ruling on the Tamimi matter discussed above, the U.S. COFC issued a judgment in favor of KBR on the common law fraud counterclaim ruling that the fraud allegations brought by the DOJ were without merit. We have been notified by the DOJ that it intends to appeal the U.S. COFC's fraud ruling and that it has filed a notice of appeal.
In August 2011, another DFAC subcontractor, Gulf Coast Catering (“GCC”), filed for arbitration in the London Court of International Arbitration to recover $9 million for payments we have withheld from them pending resolution of outstanding Form 1's with our customer. A hearing is scheduled for November 2012. As noted above, we have claims pending in the U.S. COFC to recover these amounts from the U.S. government.
Transportation costs. In 2007, the DCAA raised a question about our compliance with the provisions of the Fly America Act. During the first quarter of 2011, we received a Form 1 from the DCAA totaling $6 million for alleged violations of the Fly America Act in 2004. Subject to certain exceptions, the Fly America Act requires Federal employees and others performing U.S. Government-financed foreign air travel to travel by U.S. flag air carriers. There are times when we transported personnel in connection with our services for the U.S. military where we may not have been in compliance with the Fly America Act and its interpretations through the Federal Acquisition Regulations and the Comptroller General. Included in our September 30, 2012 and December 31, 2011 accompanying condensed consolidated balance sheets, is an accrued estimate of the cost incurred for these potentially noncompliant flights. The DCAA may consider additional flights to be noncompliant resulting in potential larger amounts of disallowed costs than the amount we have accrued. At this time, we cannot estimate a range of reasonably possible losses that may have been incurred, if any, in excess of the amount accrued. We will continue to work with our customer to resolve this matter.
In the first quarter of 2011, we received a Form 1 from the DCAA disapproving certain transportation costs totaling $27 million associated with replacing employees who were deployed in Iraq and Afghanistan for less than 179 days. The DCAA claims these replacement costs violate the terms of the LogCAP III contract which expressly disallow certain costs associated with the contractor rotation of employees who have deployed less than 179 days including costs for transportation, lodging, meals, orientation and various forms of per diem allowances. We disagree with the DCAA’s interpretation and application of the contract terms as it was applied to circumstances outside of our control including sickness, death, termination for cause or resignation and that such costs should be allowable. We do not believe we face a risk of significant loss from any disallowance of these costs in excess of the loss accruals we have recorded.
Construction services. From February 2009 through September 2010, we received Form 1’s from the DCAA disapproving $25 million in costs related to work performed under our CONCAP III contract with the U.S. Navy to provide emergency construction services primarily to Government facilities damaged by Hurricanes Katrina and Wilma. The DCAA claims the costs billed to the U.S. Navy primarily related to subcontract costs that were either inappropriately bid, included unallowable profit markup or were unreasonable. In February 2012, the Contracting Officer rendered a Contracting Officer Final Determination (“COFD”) allowing $10 million and disallowing $15 million of direct costs. We filed an appeal with the ASBCA in June 2012. As of September 30, 2012, the U.S. Navy has withheld $10 million from us. We believe we undertook adequate and reasonable steps to ensure that proper bidding procedures were followed and the amounts billed to the customer were reasonable and not in violation of the FAR. As of September 30, 2012, we have accrued our estimate of probable loss related to this matter; however, it is reasonably possible we could incur additional losses.
Investigations, Qui Tams and Litigation
The following matters relate to ongoing litigation or investigations involving U.S. government contracts.
McBride Qui Tam suit. In September 2006, we became aware of a qui tam action filed against us in the U.S. District Court in the District of Columbia by a former employee alleging various wrongdoings in the form of overbillings to our customer on the LogCAP III contract. This case was originally filed pending the government’s decision whether or not to participate in the suit. In June 2006, the government formally declined to participate. The principal allegations are that our compensation for the provision of Morale, Welfare and Recreation (“MWR”) facilities under LogCAP III is based on the volume of usage of those facilities and that we deliberately overstated that usage. In accordance with the contract, we charged our customer based on actual cost, not based on the number of users. It was also alleged that, during the period from November 2004 into mid-December 2004, we continued to bill the customer for lunches, although the dining facility was closed and not serving lunches. There are also allegations regarding housing containers and our provision of services to our employees and contractors. On July 5, 2007, the court granted our motion to dismiss the qui tam claims and to compel arbitration of employment claims including a claim that the plaintiff was unlawfully discharged. The majority of the plaintiff’s claims were dismissed but the plaintiff was allowed to pursue limited claims pending discovery and future motions. Substantially all employment claims were sent to arbitration under the Company’s dispute resolution program and were subsequently resolved in our favor. In January 2009, the relator filed an amended complaint which is pending a ruling on a discovery matter before further motions can be filed. The quantification of damages and theories that will remain has not yet been defined by the court. Trial for this matter has not been scheduled. In September 2012 we were granted a motion which limits the issues to be tried. Relator has appealed this ruling, effectively staying further action until the Court decides this issue. We believe the relator’s claim is without merit and that the likelihood that a loss has been incurred is remote. As of September 30, 2012, no amounts have been accrued.
First Kuwaiti Trading Company arbitration. In April 2008, First Kuwaiti Trading Company ("FKTC" or "First Kuwaiti"), one of our LogCAP III subcontractors, filed for arbitration of a subcontract under which KBR had leased vehicles related to work performed on our LogCAP III contract. The FKTC arbitration is being conducted under the rules of the London Court on International Arbitration and the venue is in the District of Columbia. First Kuwaiti alleged that we did not return or pay rent for many of the vehicles and seeks damages in the amount of $134 million. We filed a counterclaim to recover amounts which may ultimately be determined due to the Government for the $51 million in suspended costs as discussed in the preceding section of this footnote titled “Containers.” To date arbitration hearings for four subcontracts have taken place primarily related to claims involving unpaid rents and damages on lost or unreturned vehicles. The arbitration panel has awarded $16 million to FKTC for claims involving unpaid rents and damages on lost or unreturned vehicles, repair costs on certain vehicles, damages suffered as a result of late vehicle returns, and interest thereon, net of maintenance, storage and security costs awarded to KBR. No payments are expected to occur until all claims are arbitrated and awards finalized. Arbitration hearings for the remaining subcontracts are expected to resume in 2013. We believe any damages ultimately awarded to First Kuwaiti will be billable under the LogCAP III contract. Accordingly, we have accrued amounts payable and a related unbilled receivable for the amounts awarded to First Kuwaiti pursuant to the terms of the contract.
Electrocution litigation. During 2008, a lawsuit was filed against KBR in Pittsburgh, Pennsylvania in the Allegheny County Common Pleas Court alleging that the Company was responsible for an electrical incident which resulted in the death of a soldier. This incident occurred at the Radwaniyah Palace Complex. It is alleged in the suit that the electrocution incident was caused by improper electrical maintenance or other electrical work. KBR denies that its conduct was the cause of the event and denies legal responsibility. Plaintiffs are claiming unspecified damages for personal injury, death and loss of consortium by the parents. On July 13, 2012, the Court granted our motions to dismiss, concluding that the case is barred by the Political Question Doctrine and preempted by the Combatant Activities Exception to the Federal Tort Claims Act. The plaintiffs filed their notice of appeal with the Third Circuit Court of Appeals, and their first brief was due on October 15, 2012.
Burn Pit litigation. From November 2008 through February 2011, KBR was served with over 50 lawsuits in various states alleging exposure to toxic materials resulting from the operation of burn pits in Iraq or Afghanistan in connection with services provided by KBR under the LogCAP III contract. Each lawsuit has multiple named plaintiffs collectively representing approximately 250 individual plaintiffs. The lawsuits primarily allege negligence, willful and wanton conduct, battery, intentional infliction of emotional harm, personal injury and failure to warn of dangerous and toxic exposures which has resulted in alleged illnesses for contractors and soldiers living and working in the bases where the pits are operated. The plaintiffs are claiming unspecified damages. All of the pending cases were removed to Federal Court and have been consolidated for multi-district litigation treatment before the U.S. Federal District Court in Baltimore, Maryland. In December 2010, the Court stayed virtually all discovery proceedings pending a decision from the Fourth Circuit Court of Appeals on three other cases involving the Political Question Doctrine and other jurisdictional issues. In May 2012, the Court denied plaintiff's request for jurisdictional discovery. In June 2012, KBR filed a renewed motion to dismiss which was heard in July 2012 and we expect a ruling during the fourth
quarter of 2012. Due to the inherent uncertainties of litigation and because the litigation is at a preliminary stage, we cannot at this time accurately predict the ultimate outcome nor can we reliably estimate a range of possible loss, if any, related to this matter at this time. Accordingly, as of September 30, 2012, no amounts have been accrued.
Sodium Dichromate litigation. From December 2008 through September 2009, five cases were filed in various federal district courts against KBR by national guardsman and other military personnel alleging exposure to potentially hazardous chemicals at the Qarmat Ali Water Treatment Plant in Iraq in 2003. The majority of the cases were re-filed and consolidated into two cases, with one pending in the U.S. District Court for the Southern District of Texas, in Houston, and one pending in the U.S. District Court for the District of Oregon. Collectively, the suit represents approximately 170 individual plaintiffs all of which are current and former national guardsmen who claim they were exposed to sodium dichromate while escorting KBR employees who were working at the water treatment plant and that the defendants knew or should have known that the potentially toxic substance existed and negligently failed to protect the guardsmen from exposure. The plaintiffs are claiming unspecified damages. The U.S. Corps of Engineers (“USACE”) was contractually obligated to provide a benign site free of war and environmental hazards before KBR’s commencement of work on the site. KBR notified the USACE within two days after discovering the sodium dichromate and took effective measures to remediate the site. KBR services provided to the USACE were under the direction and control of the military and therefore, KBR believes it has adequate defenses to these claims. KBR will also assert Political Question Doctrine and Government Contractor defenses. Additionally, the U.S. Government and other studies on the effects of exposure to the sodium dichromate contamination at the water treatment plant have found no long term harm to the soldiers. However, due to the inherent uncertainties of litigation and because the litigation is in the preliminary stages, we cannot accurately predict the ultimate outcome nor can we reliably estimate a range of possible loss, if any, related to this matter. In the Texas case, the Court granted motions dismissing plaintiffs’ fraud claims, medical monitoring damages, and claims for ongoing genetic transformation injury, but denied KBR’s motion to dismiss based upon Political Question and Combatant Activity doctrines. KBR appealed this latter ruling to the Fifth Circuit Court of Appeals, and a stay order has been entered in the trial court pending outcome of the appeal. In the Oregon case, the Court denied KBR’s motion to dismiss, and thereafter denied our request to certify the ruling for immediate appeal to the Ninth Circuit Court of Appeals. On October 9, 2012, the case proceeded to trial on the merits, and is currently in trial. As of September 30, 2012, no amounts have been accrued. During the period of time since the first litigation was filed against us, we have incurred legal defense costs that we believe are reimbursable under the related customer contract. We intend to bill for these costs, and if necessary, file claims with either the U.S. COFC or ASBCA to recover the associated revenues recognized to date.
Convoy Ambush Litigation. In April 2004, a fuel convoy in route from Camp Anaconda to Baghdad International Airport for the U.S. Army under our LogCAP III contract was ambushed, resulting in deaths and severe injuries to truck drivers hired by KBR. In 2005, survivors of the drivers killed and those that were injured in the convoy filed suit in state court in Houston, Texas against KBR and several of its affiliates, claiming KBR deliberately intended that the drivers in the convoy would be attacked and wounded or killed. The suit also alleges KBR committed fraud in its hiring practices by failing to disclose the dangers associated with working in the Iraq combat zone. The case was removed to U.S. Federal District Court in Houston, Texas. After numerous motions and rulings in the trial court and appeals to U.S. Fifth Circuit Court of Appeals, in January 2012, the appellate Court granted KBR’s appeal on dispositive motions and dismissed the claims of all remaining plaintiffs on the grounds that their claims are banned by the exclusive remedy provisions of the Defense Base Act. Prior to the dismissal of the claims against KBR by the appellate Court, KBR settled the claims of one of the plaintiffs. The remaining plaintiffs sought a rehearing of the dismissal by the Fifth Circuit which was denied in April 2012. We believe the cost of settling with one of the plaintiffs is reimbursable under the related customer contract. We intend to bill for these costs, and if necessary, file claims with either the U.S. COFC or ASBCA to recover the associated revenues recognized to date. In July 2012, the plaintiffs filed a petition for a writ of certiorari in the U.S. Supreme Court. In October 2012, the plaintiffs were denied their petition for a writ of certiorari by the U.S. Supreme Court. We consider this matter concluded.
DOJ False Claims Act complaint. In April 2010, the DOJ filed a complaint in the U.S. District Court in the District of Columbia alleging certain violations of the False Claims Act related to the use of private security firms. The complaint alleges, among other things, that we made false or fraudulent claims for payment under the LogCAP III contract because we allegedly knew that they contained costs of services for or that included improper use of private security. We believe these sums were properly billed under our contract with the Army and that the use of private security was not prohibited under the LogCAP III contract. Discovery closed under the Court's scheduling order in the second quarter of 2012. The DOJ did not participate in discovery on the merits. We had several discovery motions and potentially dispositive motions pending before the Court. In August 2012, the Court ruled on a number of pending motions and granted some of our discovery requests. The Court indicated that it would consider the effect of the ASBCA ruling regarding the issues in this case. Due to the continued delays and pending motions, we continue to believe trial is unlikely to occur in 2012. Additionally, we believe the ASBCA decision interpreting the LogCAP III contract discussed above under the heading "Private Security" is sufficient to dismiss the DOJ's False Claims Act case. We continue to believe this complaint is without merit. We have not adjusted our revenues or accrued any amounts related to this matter.
Claims. Included in receivables in our condensed consolidated balance sheets are claims for costs incurred under various government contracts totaling $206 million at September 30, 2012, of which $124 million is included in “Accounts receivable” and $82 million is included in “Unbilled receivables on uncompleted contracts.” These claims relate to contracts where our costs have exceeded the customer’s funded value of the task order. The $124 million of claims included in Accounts receivable results primarily from de-obligated funding on certain task orders that were also subject to Form 1’s relating to certain DCAA audit issues discussed above. We believe such disputed costs will be resolved in our favor at which time the customer will be required to obligate funds from appropriations for the year in which resolution occurs. The remaining claims balance of $82 million primarily represents costs for which incremental funding is pending in the normal course of business. The majority of costs in this category are normally funded within several months after the costs are incurred. The claims outstanding at September 30, 2012, are considered to be probable of collection and have been previously recognized as revenue.
Note 9. Other Commitments and Contingencies
Barracuda-Caratinga Project Arbitration
In June 2000, we entered into a contract with Barracuda & Caratinga Leasing Company B.V., the project owner and claimant, to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. Petrobras is a contractual representative that controls the project owner. In November 2007, we executed a settlement agreement with the project owner to settle all outstanding project issues except for the bolts arbitration discussed below.
At Petrobras’ direction, we replaced certain bolts located on the subsea flowlines that failed through mid-November 2005, and we understand that additional bolts failed thereafter, which were replaced by Petrobras. These failed bolts were identified by Petrobras when it conducted inspections of the bolts. In March 2006, Petrobras notified us they submitted this matter to arbitration claiming $220 million plus interest for the cost of monitoring and replacing the defective stud bolts and, in addition, all of the costs and expenses of the arbitration including the cost of attorneys’ fees. The arbitration was conducted in New York under the guidelines of the United Nations Commission on International Trade Law (“UNCITRAL”).
In September 2011, the arbitration panel awarded the claimant approximately $193 million. The damages awarded were based on the panel’s estimate to replace all subsea bolts, including those that did not manifest breaks, as well as legal and other costs incurred by the claimant in the arbitration and interest thereon since the date of the award. The panel rejected our argument, and the case law relied upon by us, that we were only liable for bolts that were discovered to be broken prior to the expiration of the warranty period that ended on June 30, 2006. As of September 30, 2012, we have a liability of $210 million, including interest, to Petrobras for the failed bolts which is included in “Other current liabilities.” The liability incurred by us in connection with the arbitration is covered by an indemnity from our former parent, Halliburton. Accordingly, we have recorded an indemnification receivable from Halliburton of $210 million pursuant to the indemnification under the master separation agreement which is included in “Other current assets” as of September 30, 2012. The arbitration award payable to Petrobras will be deductible for tax purposes when paid. The indemnification payment will be treated by KBR for tax purposes as a contribution to capital and accordingly is not taxable. Halliburton has directed us to challenge the arbitration award as being defective or outside the jurisdiction of the arbitration panel. This challenge was filed in the United States District Court for the Southern District of New York on December 16, 2011. The challenge has been fully briefed to the Court and oral argument has not been scheduled. We will continue to be responsible for all ongoing legal costs associated with this matter. If the challenge to the arbitration award is successful and the award payable to Petrobras is either reduced or reversed in a future period, we would reverse the related tax benefit previously recognized as a charge to income as tax expense in that period. As of September 30, 2012, we do not believe there are any legal limitations on our ability to recover the full amount of the cash arbitration award and we intend to assert our rights under the indemnity agreement with Halliburton.
In 1997 and 1998, we entered into three contracts with PEMEX, the project owner, to build offshore platforms, pipelines and related structures in the Bay of Campeche offshore Mexico. The three contracts were known as Engineering, Procurement and Construction (“EPC”) 1, EPC 22 and EPC 28. All three projects encountered significant schedule delays and increased costs due to problems with design work, late delivery and defects in equipment, increases in scope and other changes. PEMEX took possession of the offshore facilities of EPC 1 in March 2004 after having achieved oil production but prior to our completion of our scope of work pursuant to the contract.
We filed for arbitration with the International Chamber of Commerce (“ICC”) in 2004 claiming recovery of damages of approximately $323 million for the EPC 1 project. PEMEX subsequently filed counterclaims totaling $157 million. In December 2009, the ICC ruled in our favor, and we were awarded a total of approximately $351 million including legal and administrative recovery fees as well as interest. PEMEX was awarded approximately $6 million on counterclaims, plus interest on a portion of that sum. In connection with this award, we recognized a gain of $117 million net of tax in 2009. The arbitration award is legally binding and on November 2, 2010, we received a judgment in our favor in the U.S. District Court for the Southern District of New York to recognize the award in the U.S. of approximately $356 million plus Mexican value added tax and interest thereon until paid. PEMEX initiated an appeal to the U.S. Court of Appeals for the Second Circuit and asked for a stay of the enforcement of the judgment while on appeal. The stay was granted, but PEMEX was required to post collateral of $395 million with the court registry. Appellate briefs have been filed by both parties and oral arguments were heard by the Second Circuit Court on February 2, 2012. On February 16, 2012, the Second Circuit issued an order remanding the case to the District Court to consider if the decision of the Collegiate Court in Mexico, described below, would have affected the trial court’s ruling. Both parties filed briefs and hearings were conducted in May and July 2012. The matter was briefed before the District Court in September 2012 and was stayed. KBR was ordered to seek remedies in Mexican courts, and is preparing to begin proceedings in Mexico as directed. We believe the possibility of the trial court reversing its own ruling to be remote as U.S. courts have a strong record of recognizing and enforcing international arbitration awards. However, an unfavorable ruling by the trial court could have a material adverse impact to our results of operations.
PEMEX attempted to nullify the award in Mexico which was rejected by the Mexican trial court in June 2010. PEMEX then filed an “amparo” action on the basis that its constitutional rights had been violated which was denied by the Mexican court in October 2010. PEMEX subsequently appealed the adverse decision with the Collegiate Court in Mexico on the grounds that the arbitration tribunal did not have jurisdiction and that the award violated the public order of Mexico. Although these arguments were presented in the initial nullification and amparo action, and were rejected in both cases, in September 2011, the Collegiate Court in Mexico ruled in favor of PEMEX on the amparo action. The Collegiate Court ruled that PEMEX, by administratively rescinding the contract in 2004, deprived the arbitration panel of jurisdiction thereby nullifying the arbitration award. The Collegiate Court decision is contrary to the ruling received from the ICC as well as all other Mexican courts which have denied PEMEX’s repeated attempts to nullify the arbitration award. We also believe the Collegiate Court decision is contrary to Mexican law governing contract arbitration. However, we do not expect the Collegiate Court decision to affect the outcome of the U.S. appeal discussed above or our ability to ultimately collect the ICC arbitration award in the U.S. due to the significant assets of PEMEX in the U.S. as well as the collateral posted by PEMEX with the court registry The circumstances of this matter are unique and in the unlikely event we are not able to collect the arbitration award in the U.S., we will pursue other remedies including filing a North American Free Trade Agreement (“NAFTA”) arbitration to recover the award as an unlawful expropriation of assets by the government of Mexico.
We were successful in litigating and collecting on valid international arbitration awards against PEMEX on the EPC 22 and EPC 28 projects during 2008. Additionally, PEMEX has sufficient assets in the U.S. which we believe we will be able to attach as a result of the recognition of the ICC arbitration award in the U.S. Although it is possible we could resolve and collect the amounts due from PEMEX in the next 12 months, we believe the timing of the collection of the award is uncertain and therefore, we have continued to classify the amount due from PEMEX as a long term receivable included in “Noncurrent unbilled receivable on uncompleted contracts” as of September 30, 2012. No adjustments have been made to our receivable balance since recognition of the initial award in 2009. Depending on the timing and amount ultimately settled with PEMEX, including interest, we could recognize an additional gain upon collection of the award.
In connection with the EPC 1 project, we have approximately $80 million in outstanding performance bonds furnished to PEMEX when the project was awarded. The bonds were written by a Mexican bond company and backed by a U.S. insurance company which is indemnified by KBR. As a result of the ICC arbitration award in December 2009, the panel determined that KBR had performed on the project and recovery on the bonds by PEMEX was precluded. PEMEX filed an action in Mexico in June 2010 against the Mexican bond company to collect the bonds even though the arbitration award ruled that the bonds were to be returned to KBR. In May 2011, the Mexican trial court ruled PEMEX could collect the bonds even though PEMEX at the time was unsuccessful in its attempts to nullify the arbitration award. The decision was immediately appealed by the bonding company and PEMEX was not able to call the bonds while on appeal. In October 2011, we were officially notified that the appellate court ruled in favor of PEMEX, therefore allowing PEMEX to call the bonds. In December 2011, we and the Mexican bond company stayed payment of the bonds by filing a direct amparo action in the Mexican court, and we filed a bond to cover interest accruing during the pendency of our amparo action. During the third quarter of 2012, the Collegiate Court hearing the amparo action has asked the lower court to review the proceedings. In the event our amparo action is unsuccessful and the U.S. insurance company makes payment to the Mexican bonding company, we may be required to indemnify the U.S. insurance company. In this event, we will pursue other remedies including seeking relief in the U.S. District Court for the Southern District of New York
or the filing of a NAFTA arbitration to recover the bonds as an unlawful expropriation of assets by the government of Mexico.
In April 2001, our subsidiary, MWKL, entered into lump-sum contracts with Fina Antwerp Olefins (FAO), a joint venture between ExxonMobil and Total, to perform EPC services for FAO’s revamp and expansion of an existing olefins plant in Belgium. The contracts had an initial value of approximately €113 million. Upon execution of the contracts, MWKL was confronted with a multitude of changes and issues on the project resulting in significant cost overruns and schedule delays. The project was completed in October 2003. In 2005, after unsuccessful attempts to engage FAO in negotiations to settle MWKL’s outstanding claims, MWKL filed suit against FAO in the Commercial Court of Antwerp, Belgium, seeking to recover amounts for rejected change requests, disruption, schedule delays and other items. MWKL sought the appointment of a court expert to determine the technical aspects of the disputes between the parties upon which the judge could rely for allocating liability and determining the final amount of MWKL’s claim against FAO. FAO filed a counterclaim in 2006 claiming recovery of additional costs for various matters including, among others, project management, temporary offices, security, financing costs, deficient work items and disruption of activities some of which we believe is either barred by the language in the contract or has not been adequately supported. Although the court expert has issued several preliminary reports which support our claim receivable, a final report has yet to be issued that addresses the full value of KBR’s claims. We currently expect the court expert to release a final report in December 2012. We do not believe we face a risk of significant loss associated with the value of the claim receivable recorded on our balance sheets or FAO’s counterclaims. As of September 30, 2012, no amounts have been accrued related to the counterclaim.
Letters of credit
In connection with certain projects, we are required to provide letters of credit, surety bonds or guarantees to our customers. Letters of credit are provided to certain customers and counter-parties in the ordinary course of business as credit support for contractual performance guarantees, advanced payments received from customers, and future funding commitments. We have approximately $2 billion in committed and uncommitted lines of credit to support the issuance of letters of credit, and we have utilized $671 million of our line of credit capacity as of September 30, 2012. Surety bonds are also posted under the terms of certain contracts to guarantee our performance. The letters of credit outstanding included $222 million issued under our Credit Agreement and $449 million issued under uncommitted bank lines at September 30, 2012. Of the total letters of credit outstanding, $272 million relate to our joint venture operations and $9 million of the letters of credit have terms that could entitle a bank to require additional cash collateralization on demand. As the need arises, future projects will be supported by letters of credit issued under our Credit Agreement or other lines of credit arranged on a bilateral, syndicated or other basis. We believe we have adequate letter of credit capacity under our Credit Agreement and bilateral lines of credit to support our operations for the next twelve months.
As of September 30, 2012, we had commitments to provide funds to our privately financed projects of $9 million, primarily related to future equity funding on our Allenby and Connaught project coming due within one year. Our commitments to fund our privately financed projects are supported by letters of credit as described above.
Note 10. Transactions with Former Parent
Pursuant to our master separation agreement, we agreed to indemnify Halliburton for, among other matters, all past, present and future liabilities related to our business and operations. We agreed to indemnify Halliburton for liabilities under various outstanding and certain additional credit support instruments relating to our businesses and for liabilities under litigation matters related to our business. Halliburton agreed to indemnify us for, among other things, liabilities unrelated to our business, for certain other agreed matters relating to the investigation of FCPA and related corruption allegations and the Barracuda-Caratinga project and for other litigation matters related to Halliburton’s business. See Note 9. The tax sharing agreement provides for certain allocations of U.S. income tax liabilities and other agreements between us and Halliburton with respect to tax matters.
As of September 30, 2012, “Due to former parent, net” was approximately $57 million and was comprised primarily of estimated amounts owed to Halliburton under the tax sharing agreement for income taxes. Our estimate of amounts due to Halliburton under the tax sharing agreement was $49 million at September 30, 2012 and relates to income tax adjustments paid by Halliburton subsequent to our separation that were directly attributable to us, primarily for the years from 2001 through 2006. The remaining balance of $8 million included in “Due to former parent, net” as of September 30, 2012 is associated with various other amounts payable to Halliburton arising under the other separation agreements.
During the fourth quarter of 2011, Halliburton provided notice and demanded payment for amounts significantly greater than our accrued liability that it alleges are owed by us under the tax sharing agreement for various other tax-related transactions pertaining to periods prior to our separation from Halliburton. We believe that the amount in the demand is invalid based on our assessment of Halliburton’s methodology for computing the claim. Based on advice from internal and external legal counsel, we do not believe that Halliburton has a legal entitlement to payment of the amount in the demand. However, although we believe we have appropriately accrued for amounts owed to Halliburton based on our interpretation of the tax sharing agreement, there may be changes to the amounts ultimately paid to or received from Halliburton under the tax sharing agreement upon final settlement. On July 3, 2012, KBR requested an arbitration panel be appointed to resolve certain intercompany issues arising under the master separation agreement in effect between the companies. We believe the intercompany issues were settled and released as a result of our separation from Halliburton in 2007. On July 10, 2012, Halliburton filed a complaint in Texas State Court seeking to compel resolution of all issues under the tax sharing agreement rather than the master separation agreement. In October 2012, the Court determined that arbitration under the master separation agreement should decide the issues, and we are moving forward with the selection of arbitrators. The remaining tax-related issues in dispute will be resolved by a designated "accounting referee" as provided for under the terms of the tax sharing agreement.
As of September 30, 2012, included in “Other assets” is an income tax receivable of approximately $18 million related to a foreign tax credit generated as a result of a final settlement we paid to a foreign taxing authority in 2011 for a disputed tax matter that arose prior to our separation from Halliburton. In order to claim the tax credit, we requested, and Halliburton agreed to and did file an amended U.S. Federal tax return for the period in which the disputed tax liability arose. However, Halliburton notified us that it does not intend to remit to us the refund received or to be received by Halliburton as a result of the amended return. KBR disputes Halliburton’s position on this matter and believes it has legal entitlement to the $18 million refund. We intend to vigorously pursue collection of this amount and certain other unrecorded counterclaims. The timing of ultimate resolution of these matters will depend in part on future discussion with Halliburton and arbitration under the terms of the separation agreements as discussed above.
As discussed above under “Barracuda-Caratinga Project Arbitration,” we have recorded an indemnification receivable due from Halliburton of approximately $210 million, including interest, associated with our estimated liability in the bolts matter which is included in “Other current assets” as of September 30, 2012.
Note 11. Income Taxes
Excluding the noncash goodwill impairment charge of $178 million , which is not deductible for U.S. taxes, and discrete items, our adjusted effective tax rate was 29% for both the three and nine months ended September 30, 2012. The adjusted effective tax rate includes increases of 2% and 1%, respectively, for the three and nine months as a result of incremental income taxes on certain undistributed foreign earnings in Australia that were previously deemed to be permanently reinvested. The effective tax rate excluding discrete items was lower than the U.S. statutory rate of 35% due to favorable tax rate differentials on foreign earnings and lower tax expense on foreign income from unincorporated joint ventures, and tax benefits from incorporated joint ventures. In the three and nine months ended September 30, 2012, we recognized discrete net tax benefits of approximately $2 million and $42 million. The net tax benefits for the nine months primarily relate to the recognition of previously unrecognized tax benefits related to tax positions taken in prior years due to progress in resolving transfer pricing matters with certain taxing jurisdictions, statute expirations on certain domestic tax matters and other reductions to foreign tax exposures as well as discrete tax benefits related to deductions arising from an unconsolidated joint venture in Australia.
Our effective tax rate excluding discrete items was approximately 27% and 29% for the three and nine months ended September 30, 2011. Our effective tax rate excluding discrete items for the three and nine months ended September 30, 2011 was lower than the U.S. statutory rate of 35% primarily due to favorable tax rate differentials on foreign earnings and lower tax expense on foreign income from unincorporated joint ventures. During the third quarter of 2011, we recognized discrete tax benefits including a $68 million tax benefit related to the arbitration award against KBR associated with the Barracuda-Caratinga project in Brazil as well as a $24 million tax benefit related to the reduction of deferred tax liabilities associated with an unconsolidated joint venture in Australia resulting in a negative effective tax rate that was not meaningful for the three months ended September 30, 2011 and an effective tax rate of 2% for the nine months ended September 30, 2011. In September 2011, the arbitration panel in the Barracuda-Caratinga arbitration awarded Petrobras approximately $193 million (see Note 9). This expense will be deductible for tax purposes when paid. The indemnification payment will be treated by KBR for tax purposes as a contribution to capital and accordingly is not taxable. Consequently, the arbitration ruling resulted in a tax benefit in the third quarter of 2011. We also reduced certain deferred tax liabilities recorded in prior periods as a result of additional information received during the third quarter of 2011 regarding the tax liability that will be owed upon the planned liquidation of an Australian unconsolidated joint venture that is in receivership. In the first nine months of 2011, we recognized discrete tax benefits from the
execution of tax planning strategies, the release of a tax reserve due to expiration of a statute and from the reduction of deferred tax liabilities as a result of changes in estimates of the tax liabilities related to the planned liquidation of an unconsolidated joint venture in Australia that is in receivership.
Note 12. Shareholders’ Equity
The following tables summarize our shareholders’ equity activities during the nine months ended September 30, 2012 and 2011:
(a) During the third quarter of 2012, we recorded out-of-period adjustments in our deferred tax accounts, most of which relate to years before 2010. These adjustments are not material to the third quarter of 2012 or the periods to which they relate. The out-of-period adjustments were $3 million to our current period tax expense and $9 million to various equity accounts.
Accumulated other comprehensive loss consisted of the following balances:
Note 13. Fair Value Measurements
The financial assets and liabilities measured at fair value on a recurring basis at September 30, 2012 are included below:
Derivative instruments. Currency derivative instruments are carried on the condensed consolidated balance sheet at fair value and are primarily based upon market observable inputs and significant other observable inputs. We manage our currency exposures through the use of foreign currency derivative instruments denominated in our major currencies, which are generally the currencies of the countries for which we do the majority of our international business. We utilize derivative instruments to manage the foreign currency exposures related to specific assets and liabilities that are denominated in foreign currencies, and to manage forecasted cash flows denominated in foreign currencies generally related to long-term engineering and construction
projects. The purpose of our foreign currency risk management activities is to protect us from the risk that the eventual dollar cash flow resulting from the sale and purchase of products and services in foreign currencies will be adversely affected by changes in exchange rates.
Marketable securities. We use quoted market prices and other observable inputs to determine the fair value of our marketable securities. These financial instruments primarily consist of mutual funds, exchange-traded fixed income securities and money market accounts.
Goodwill impairment review. In accordance with FASB ASC 350-20, the goodwill of our Minerals reporting unit, which is part of our IGP segment, was written down to its implied fair value of $85 million from its carrying value of $263 million at December 31, 2011, resulting in an impairment charge of $178 million in the third quarter of 2012.
For purposes of our interim impairment test, the fair value of the Minerals reporting unit was determined using a combination of two methods; one based on market earnings multiples of peer companies identified for the business unit (the market approach), and a discounted cash flow model with estimates of cash flows based on internal forecasts of revenues and expenses over a 10 year period plus a terminal value period (the income approach). The market approach estimates fair value by applying earnings and revenue market multiples to the reporting unit's operating performance for the trailing twelve-month period. The market multiples are derived from comparable publicly traded companies with operating and investment characteristics similar to those of our Minerals reporting units. The income approach estimates fair value by discounting the reporting unit's estimated future cash flows using a weighted-average cost of capital that reflects current market conditions and the risk profile of the business unit.
To arrive at the Minerals reporting unit's future cash flows, we use estimates of economic and market information, including growth rates in revenues, costs, and estimates of future expected changes in operating margins, tax rates, and cash expenditures. Other significant estimates and assumptions include terminal value growth rates, future estimates of capital expenditures and changes in future working capital requirements. Under the income approach, we applied a risk-adjusted discount rate of 16% to the future cash flows from the Mineral reporting unit. In addition to the earnings multiples and the discount rates disclosed above, certain other judgments and estimates are used to prepare the goodwill impairment test. If market conditions change compared to those used in our market approach, or if actual future results of operations fall below the projections used in the income approach, our goodwill could become further impaired in the future.
Note 14. Equity Method Investments and Variable Interest Entities
We conduct some of our operations through joint ventures which are in partnership, corporate, undivided interest and other business forms and are principally accounted for using the equity method of accounting. Additionally, the majority of our joint ventures are also variable interest entities which are further described below.
Variable Interest Entities
The majority of our joint ventures are variable interest entities. We account for variable interest entities (“VIEs”) in accordance with ASC 810 – Consolidation which requires the consolidation of VIEs in which a company has both the power to direct the activities of the VIE that most significantly impact the VIE’s economic performance and the obligation to absorb losses or the right to receive the benefits from the VIE that could potentially be significant to the VIE. If a reporting enterprise meets these conditions, then it has a controlling financial interest and is the primary beneficiary of the VIE.
We assess all newly created entities and those with which we become involved to determine whether such entities are VIEs and, if so, whether or not we are their primary beneficiary. Most of the entities we assess are incorporated or unincorporated joint ventures formed by us and our partner(s) for the purpose of executing a project or program for a customer and are generally dissolved upon completion of the project or program. Many of our long-term energy-related construction projects in our Hydrocarbons business group are executed through such joint ventures. Typically, these joint ventures are funded by advances from the project owner, and accordingly, require little or no equity investment by the joint venture partners but may require subordinated financial support from the joint venture partners such as letters of credit, performance and financial guarantees or obligations to fund losses incurred by the joint venture. Other joint ventures, such as privately financed initiatives in our Ventures business unit, generally require the partners to invest equity and take an ownership position in an entity that manages and operates an asset post construction.
As required by ASC 810-10, we perform a qualitative assessment to determine whether we are the primary beneficiary once an entity is identified as a VIE. Thereafter, we continue to re-evaluate whether we are the primary beneficiary of the VIE in
accordance with ASC 810-10. A qualitative assessment begins with an understanding of the nature of the risks in the entity as well as the nature of the entity’s activities including terms of the contracts entered into by the entity, ownership interests issued by the entity and how they were marketed, and the parties involved in the design of the entity. We then identify all of the variable interests held by parties involved with the VIE including, among other things, equity investments, subordinated debt financing, letters of credit, and financial and performance guarantees, and significant, contracted service providers. Once we identify the variable interests, we determine the activities that are most significant to the economic performance of the entity and which variable interest holder has the power to direct those activities. Though infrequent, some of our assessments reveal no primary beneficiary because the power to direct the most significant activities that impact the economic performance is held equally by two or more variable interest holders who are required to provide their consent prior to the execution of their decisions. Most of the VIEs with which we are involved have relatively few variable interests and are primarily related to our equity investment, significant service contracts, and other subordinated financial support.
The following is a summary of the significant variable interest entities in which we have a significant variable interest, but we are not the primary beneficiary:
U.K. Road projects. We are involved in four privately financed projects, executed through joint ventures, to design, build, operate, and maintain roadways for certain government agencies in the United Kingdom. We have a 25% ownership interest in each of these joint ventures and account for them using the equity method of accounting. The joint ventures have obtained financing through third parties that is nonrecourse to the joint venture partners. These joint ventures are variable interest entities; however, we are not the primary beneficiary. Our maximum exposure to loss represents our equity investments in these ventures.
Fermoy Road project. We participate in a privately financed project executed through certain joint ventures formed to design, build, operate, and maintain a toll road in southern Ireland. The joint ventures were funded through debt and were formed with minimal equity. These joint ventures are variable interest entities; however, we are not the primary beneficiary. We have up to a 25% ownership interest in the project’s joint ventures, and we are accounting for these interests using the equity method of accounting.
Allenby & Connaught project. In April 2006, Aspire Defence, a joint venture between us, Carillion Plc. and two financial investors, was awarded a privately financed project contract, the Allenby & Connaught project, by the United Kingdom Ministry of Defense (“MoD”) to upgrade and provide a range of services to the British Army’s garrisons at Aldershot and around Salisbury Plain in the United Kingdom. In addition to a package of ongoing services to be delivered over 35 years, the project includes a nine-year construction program to improve soldiers’ single living, technical and administrative accommodations, along with leisure and recreational facilities. Aspire Defence manages the existing properties and is responsible for design, refurbishment, construction
and integration of new and modernized facilities. We indirectly own a 45% interest in Aspire Defence, the project company that is the holder of the 35-year concession contract. In addition, we own a 50% interest in each of two joint ventures that provide the construction and the related support services to Aspire Defence. As of September 30, 2012, our performance through the construction phase is supported by $30 million in letters of credit. Furthermore, our financial and performance guarantees are joint and several, subject to certain limitations, with our joint venture partners. The project is funded through equity and subordinated debt provided by the project sponsors and the issuance of publicly held senior bonds which are nonrecourse to us. The entities we hold an interest in are variable interest entities; however, we are not the primary beneficiary of these entities. We account for our interests in each of the entities using the equity method of accounting. Our maximum exposure to construction and operating joint venture losses is limited to the funding of any future losses incurred by those entities under their respective contracts with the project company. As of September 30, 2012, our assets and liabilities associated with our investment in this project, within our condensed consolidated balance sheet, were $27 million and $2 million, respectively. The $32 million difference between our recorded liabilities and aggregate maximum exposure to loss was primarily related to our equity investments and $9 million remaining commitment to fund subordinated debt to the project in the future.
EBIC Ammonia project. We have an investment in a development corporation that has an indirect interest in the Egypt Basic Industries Corporation (“EBIC”) ammonia plant project located in Egypt. We performed the engineering, procurement and construction (“EPC”) work for the project and completed our operations and maintenance services for the facility in the first half of 2012. We own 65% of this development corporation and consolidate it for financial reporting purposes. The development corporation owns a 25% ownership interest in a company that consolidates the ammonia plant which is considered a variable interest entity. The development corporation accounts for its investment in the company using the equity method of accounting. The variable interest entity is funded through debt and equity. Indebtedness of EBIC under its debt agreement is non-recourse to us. We are not the primary beneficiary of the variable interest entity. As of September 30, 2012, our assets and liabilities associated with our investment in this project, within our condensed consolidated balance sheet, were $76 million and $3 million, respectively. The $46 million difference between our recorded liabilities and aggregate maximum exposure to loss was related to our investment balance and other receivables in the project as of September 30, 2012.
Inpex LNG project. In January 2012, we signed an agreement to provide fixed-price and cost-reimbursable EPC services to construct the Inpex Ichthys Onshore LNG Export Facility in Darwin, Australia (“Inpex LNG project”). The project will be executed using two joint ventures in which we own a 30% equity interest. The investments are accounted for using the equity method of accounting. At September 30, 2012, our assets and liabilities associated with our investment in this project recorded in our condensed consolidated balance were $55 million and $6 million, respectively. The $49 million difference between our recorded liabilities and aggregate maximum exposure to loss was related to our equity investment and other receivables due from the entity as of September 30, 2012.
The following is a summary of the significant VIEs where we are the primary beneficiary:
Fasttrax Limited project. In December 2001, the Fasttrax Joint Venture (the “JV”) was created to provide to the MoD a fleet of new heavy equipment transporters (“HETs”) capable of carrying a Challenger II tank. The JV owns, operates and maintains the HET fleet and provides heavy equipment transportation services to the British Army. The JV’s entity structure includes a parent entity and its 100%-owned subsidiary, Fasttrax Ltd (the “SPV”). KBR and its partner each own 50% of the parent entity.
The JV’s purchase of the assets was funded through the issuance of several series guaranteed secured bonds. The bonds are guaranteed by Ambac Assurance U.K. Ltd under a policy that guarantees the schedule of principal and interest payments to the bond trustee in the event of non-payment by Fasttrax. The total amount of non-recourse project-finance debt of a VIE consolidated by KBR at September 30, 2012, is summarized in the following table and are also reflected on the face of our condensed consolidated balance sheet as “Non-recourse project-finance debt.” The secured bonds are an obligation of Fasttrax Limited and will never be a debt obligation of KBR because they are non-recourse to the joint venture partners. Accordingly, in the event of a default on the term loan, the lenders may only look to the resources of Fasttrax Limited for repayment. Assets collateralizing the JV’s senior bonds include cash and equivalents of $29 million and property, plant, and equipment of approximately $73 million, net of accumulated depreciation of $51 million as of September 30, 2012.
Consolidated amounts of non-recourse project-finance debt of a VIE
Escravos Gas-to-Liquids (“GTL”) project. During 2005, we formed a joint venture to engineer and construct a gas monetization facility. We own 50% equity interest in the joint venture and determined that we are the primary beneficiary of the joint venture, which is consolidated for financial reporting purposes. There are no consolidated assets that collateralize the joint venture’s obligations. However, at September 30, 2012 and December 31, 2011, the joint venture had approximately $128 million and $119 million of cash, respectively, which mainly relate to advanced billings in connection with the joint venture’s obligations under the EPC contract.
Pearl GTL project. In July 2006, we were awarded, through a 50%-owned joint venture, a contract with Qatar Shell GTL Limited to provide project management and cost-reimbursable engineering, procurement and construction management services for the Pearl GTL project in Ras Laffan, Qatar. The project, which was substantially complete as of December 31, 2011, consists of gas production facilities and a GTL plant. The joint venture is considered a VIE. We consolidate the joint venture for financial reporting purposes because we are the primary beneficiary.
Gorgon LNG project. We have a 30% ownership in an Australian joint venture which was awarded a contract by Chevron for cost-reimbursable FEED and EPCM services to construct a LNG plant. The joint venture is considered a VIE, and, as a result of our being the primary beneficiary, we consolidate this joint venture for financial reporting purposes.
Note 15. Retirement Plans
The components of net periodic benefit cost related to pension benefits for the three and nine months ended September 30, 2012 and 2011 were as follows:
For the nine months ended September 30, 2012, we contributed approximately $20 million of the $26 million we currently expect to contribute to our international plans in 2012, and approximately $3 million of the $4 million we currently expect to contribute to our domestic plans in 2012.
Note 16. New Accounting Pronouncements
During the third quarter of 2012, the FASB issued Accounting Standards Update (ASU) No. 2012-02, Intangibles -Goodwill and Other (Topic 350): Testing Indefinite-Lived Intangible Assets for Impairment. ASU 2012-02 states that an entity has the option first to assess qualitative factors to determine whether the existence of events and circumstances indicates that it is more likely than not that the indefinite-lived intangible asset is impaired. If, after assessing the totality of events and circumstances, an entity concludes that it is not more likely than not that the indefinite-lived intangible asset is impaired, then the entity is not required to take further action. An entity also has the option to bypass the qualitative assessment for any indefinite-lived intangible asset in any period and proceed directly to performing the quantitative impairment test. ASU 2012-02 is effective for annual and interim impairment tests performed for fiscal years beginning after September 15, 2012, and early adoption is permitted. The adoption of this accounting standard is not expected to have a material impact on our financial position, results of operations, cash flows and disclosures.
Note 17. Subsequent Event
On October 15, 2012, we entered into an agreement to sell our Clinton Drive property. The sale is subject to customary closing conditions and is expected to close in the fourth quarter of 2012. Upon closing, we expect to report a gain on sale.
Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations
The purpose of management’s discussion and analysis (“MD&A”) is to disclose material changes in our financial condition since the most recent fiscal year-end and results of operations during the current fiscal period as compared to the corresponding period of the preceding fiscal year. The MD&A should be read in conjunction with the condensed consolidated financial statements and accompanying notes and our 2011 Annual Report on Form 10-K.
Business Environment and Results of Operations
We provide a full range of engineering, procurement and construction services for large and complex upstream and downstream projects, including LNG and GTL facilities, onshore and offshore oil and gas production facilities, refining, biofuels and other projects. We serve customers in the gas monetization, oil and gas, petrochemical, refining and chemical markets throughout the world. Our projects are generally long term in nature and are impacted by factors including market conditions, financing arrangements, governmental approvals and environmental matters. Demand for our services depends primarily on our customers’ capital expenditures in our construction market sectors.
Capital expenditures in our petroleum and petrochemical markets are driven by global and regional economic growth expectations reflected in a long global spending cycle. The spending cycle is moderated by fluctuations in crude oil prices and chemical feedstock costs including natural gas prices, and is also partially subject to financial shock. The hydrocarbons market in most international regions has improved from the downturn that occurred as a result of the worldwide economic recession. We now see long term growth in environmentally and economically driven energy projects including demand for related licensed process technologies, offshore oil and gas production, LNG, biofuels, motor fuels, chemicals and fertilizers. Upstream and downstream investment plans are advancing in such resource rich areas as the Middle East, Brazil, North Sea and East and West Africa. LNG prospects continue to develop in the Asia-Pacific region, as well as in East Africa and North America as a result of the recent gas discoveries. Each of these trends lends to our particular capability to deliver large projects in remote locations and harsh environments.
Abundant shale gas supplies and resulting low prices in North America are driving renewed interest in petrochemical project investments. Feasibility studies and front-end engineering and design projects continue to grow, reflecting clients’ intentions to invest in capital-intensive energy projects that utilize our process technologies and EPC project delivery skills.
Infrastructure, Government and Power Markets (“IGP”)
A significant portion of our IGP business group’s current activities supports the United States’ and the United Kingdom’s government operations in Iraq, Afghanistan and in other parts of the Middle East region. As a defense contractor, our financial performance is impacted by the allocation and prioritization of U.S. defense spending and sequestration is one of those impacts. The logistics support services that we provide to the U.S. government are delivered under our LogCAP IV contract and other competitively bid contracts. As a result of withdrawal of U.S. combat troops in Iraq, we demobilized our operations under the LogCAP III contract, which effectively ended in December 2011, while continuing to support the U.S. Department of State presence in Iraq under LogCAP IV. Although, we expect the volume of services we provide to the U.S. and U.K. governments in the Middle East to continue to decline over the next few years as troop counts are drawn down, we see increased spending for logistics and infrastructure for these clients as troops and equipment return to home base. We also see increased infrastructure spending by Middle Eastern governments as a core opportunity.
We operate in diverse civil infrastructure markets, including transportation, water and waste treatment and facilities. In addition to U.S. state, local and federal agencies, we provide these services to governments around the world including the U.K., Australia and the Middle East. There has been a general trend of under-investment in public infrastructure, particularly related to the quality of water, wastewater, roads and transit, rail, airports, and educational facilities where demand for expanded and improved infrastructure has historically outpaced funding. We have seen increased activity related to these types of projects particularly in the Middle East; however, the global economic recession has caused markets to remain flat in the U.S. and the U.K., which has resulted in delays or slow start-ups to major projects.
In the industrial sector, we operate in a number of markets, including utility and non-utility power, forest products, advanced manufacturing, mining, minerals and metals and consumer products, both domestically and internationally. Forest products, advanced manufacturing and consumer products are experiencing modest market improvements. However, the mining, minerals and metals markets are experiencing a decline driven in U.S. demand for commodities. We see modest market improvements internationally related to mining, minerals and metals markets driven by international commodity demand growth. In the power sector, we serve regulated utilities, power cooperatives, municipalities and various non-regulated providers, primarily in the U.S. and U.K. markets. The power sector continues to be driven by long-term economic and demographic trends and changes in environmental regulations. Projects in the power sector are currently concentrated in emissions control, repowering, renewable power and new gas-fired power generation.
We provide a wide range of construction and maintenance services to a variety of industries in the U.S. and Canada, including forest products, power, commercial and institutional buildings, general industrial and manufacturing. Demand for industrial construction services is increasing markedly in Canada, while the commercial building market shows early signs of improvement.
For a more detailed discussion of the results of operations for each of our business groups and business units, corporate general and administrative expense, income taxes and other items, see “Results of Operations” below.
Interim Goodwill Impairment Review
In the third quarter of 2012, during the course of our annual strategic planning process, we identified a deterioration in economic conditions in the minerals markets and less than expected actual and projected income and cash flows for the Minerals reporting unit, which reduced forecasts of the sales, operating income and cash flows expected in 2013 and beyond.
As a result of these triggering events, we performed an interim goodwill impairment test on our Minerals reporting unit, which is part of our IGP segment and recorded a noncash goodwill impairment charge of $178 million in this quarter. See the subheading "Interim Goodwill Impairment Review" of the "Liquidity and Capital Resources" section for additional information.
Results of Operations
We analyze the financial results for each of our four business groups including the related business units within Hydrocarbons and IGP. The business groups presented are consistent with our reportable segments discussed in Note 5 to our condensed consolidated financial statements. While certain of the business units and product service lines presented below do not meet the criteria for reportable segments in accordance with FASB ASC 280 – Segment Reporting, we believe this supplemental information is relevant and meaningful to our investors. In the first quarter of 2012, we began reporting the Infrastructure and Minerals as separate business units. Prior periods have been conformed to the current presentation.
For purposes of reviewing the results of operations, “business group income” is calculated as revenue less cost of services managed and reported by the business group and are directly attributable to the business group. Business group income excludes unallocated corporate, general, and administrative expenses and other non-operating income and expense items.
Gas Monetization. In the third quarter of 2012, Gas Monetization revenue decreased $23 million compared to the third quarter of 2011. Revenue decreased $152 million due to reductions in revenue from GTL and LNG projects that were nearing completion, partially offset by change orders which revised estimated cost to complete for the Skikda LNG project, milestone incentive awards for the Gorgon LNG project, and progress on the Ichthys LNG project. Revenue from Gorgon and Ichthys projects increased $127 million in the aggregate in the third quarter of 2012 compared to the third quarter of 2011.
Job income in the third quarter of 2012 increased $95 million compared to the same period of the prior year primarily due to change orders which revised estimated cost to complete for the Skikda LNG project, milestone awards for the Gorgon LNG project, as well as continued progress on the Ichthys LNG project. These gains were partially offset by lower progress on a GTL and other projects nearing completion in the third quarter of 2012.
Oil & Gas. Oil & Gas revenue and job income